adroitpmc logo
Follow us on
LinkedIn Profile
India
+91 9585 465 919
+91 6382 063 295
madhu@adroitpmc.com
ram.s@adroitpmc.com
Oman
+968 9380 0315
info-me@adroitpmc.com
manikandan@adroitpmc.com

According to this approach when neither of the concurrent cause is dominant the delay should be shared between the contractor and the employer.

👉 Similar approach was followed by different courts such as the United Arab Emirates and the hongkong.

The Hong Kong High Court in
Hing Construction Co Ltd v Boost Investments Ltd
expressly approved and followed the City Inn judgment of the Scottish Courts.

Law in India:

👉 The law regarding the delay in performance of the contract is codified under the Indian Contract Act 1872, section 55 and 56.

👉 If the delay is caused in the completion of the contract and for such delay, a belated performance is accepted by the contractor then he would not be entitled to any claim for any loss caused by non-performance for such reciprocal promise unless a notice regarding the same has be delivered to the employer.

👉 Under the Indian law where the contractor has agreed not to claim any damages as a result of delay in completion of the project, the contractor can still be entitled to damages under some situation like when the contractor repudiates the contract under section 55 of the Indian contract act or if the employer gives extension of time by entering into to supplement agreement and making it clear that the escalation cost would be paid.


Disclaimer

This website has been designed only for the purposes of dissemination of basic information on ADROIT; information which is otherwise available on the internet, various public platforms and social media. Careful attention has been given to ensure that the information provided herein is accurate and up-to-date.

This website is not an attempt to advertise or solicit clients and does not seek to create or invite any lawyer-client relationship. The links provided on this website are to facilitate access to basic information on ADROIT, and, to share the various thought leadership initiatives undertaken by it. The content herein or on such links should not be construed as a legal reference or legal advice. Readers are advised not to act on any information contained herein or on the links and should refer to legal counsels and experts in their respective jurisdictions for further information and to determine its impact.

Terms of use and Privacy policy