Follow us on
LinkedIn Profile
The contractor sought compensation for additional costs arising from an extended period of project execution. The employer argued that the contract contained no provision allowing the contractor to claim any costs related to the EoT.
The case turned upon the interpretation of Articles 199 and 207 of the UAE Civil Transactions Law, which emphasize the significance of a valid cause and subject matter for a contractual obligation to be legally enforceable. The Court, applying these provisions, found that the contractor’s claim for additional costs lacked a legitimate contractual or legal basis since there was no provision in the contract allowing such a claim. The EoT claim was purely for additional time and not for additional costs.
This judgment showcases how the courts can, and will, enforce the strict letter of the contract, highlighting the importance of precise contractual wording. The contractor could not claim additional costs because the contract did not explicitly provide for such a claim in the event of an EoT. This indicates that, in EOT claims, courts are unlikely to imply terms or interpret contracts generously.
It should be noted that the Court also reinforced the employer’s obligation to compensate the contractor for the contracted works upon their completion. This reciprocal obligation mirrors the contractor’s commitment to finish the work in the agreed-upon time, further reinforcing the symmetrical nature of construction contracts.
Interestingly, the court rejected the notion that the extension of the contract duration would equate to a contractual amendment leading to additional obligations.
The contractor’s claim for additional expenses arising from the extension period was deemed invalid, emphasizing that the performance of contractual obligations during an extended period does not grant the right to additional remuneration unless explicitly agreed in the contract.
In conclusion, this judgment from the Dubai Cassation Court reaffirms the criticality of meticulous contractual drafting and provides a cautionary tale for contractors entering into EOT claims. It reinforces the need to ensure that provisions allowing for additional costs during an EoT are included in the contract. Moreover, it reiterates the importance of careful contract management to ensure contractual obligations are met and rights are adequately protected during the project lifecycle.
The decision underscores the need for parties to consider all possible scenarios and articulate their mutual obligations comprehensively. Ultimately, it serves as a reminder that the law does not provide a safety net for those who fail to take the necessary precautions in their contracts.
The burden lies with the parties to negotiate and agree on all material terms, including those related to EoT claims.
#court #disputes #middleeast
Choose ADROIT as your Expert Advisor!
A-202 Oak Canopy, Trichy Road,
Coimbatore - 641 005,
Tamil Nadu, India.
Post Box 228, Postal Code 211,
Muscat - Oman.
This website has been designed only for the purposes of dissemination of basic information on ADROIT; information which is otherwise available on the internet, various public platforms and social media. Careful attention has been given to ensure that the information provided herein is accurate and up-to-date.
This website is not an attempt to advertise or solicit clients and does not seek to create or invite any lawyer-client relationship. The links provided on this website are to facilitate access to basic information on ADROIT, and, to share the various thought leadership initiatives undertaken by it. The content herein or on such links should not be construed as a legal reference or legal advice. Readers are advised not to act on any information contained herein or on the links and should refer to legal counsels and experts in their respective jurisdictions for further information and to determine its impact.